UMD Griggs Hall PODS K and L Abatement

The University of Minnesota is seeking proposals for asbestos abatement and interior demolition work in Griggs Hall, located on the Duluth campus. The project involves the renovation of PODS K and L, and the selected respondent will be required to provide a lump sum base bid for the work. The project is expected to start on September 29, 2026, and be completed by November 20, 2026. The university is looking for a responsible contractor that meets the minimum criteria set forth in Minnesota Statutes, Section 16C.285. • The project requires the respondent to provide information on their team's qualifications, project approach, and work plan. • The respondent must also provide a draft critical path method schedule and a project cost breakdown. • The university will evaluate proposals based on criteria such as team qualifications, project approach, and cost. • The selected respondent will be required to sign a contract with the university and provide a certificate of insurance and payment and performance bonds.