Firewheel 5.0 MG Ground Storage Tank Rehabilitation

The City of Garland is seeking a contractor to rehabilitate the Firewheel 5.0 MG Ground Storage Tank. The project involves the removal and replacement of the tank's coating system, as well as other related work. The contractor will be required to furnish all labor, materials, equipment, and incidentals necessary to complete the project. The contract will be awarded to the vendor submitting the most advantageous offer considering the relative importance of price and other evaluation factors. • The project includes the application of a new coating system to the tank's interior and exterior surfaces. • The contractor will be required to perform surface preparation, including abrasive blasting and cleaning, prior to applying the coating system. • The contract includes a provision for liquidated damages in the event of delays or failure to complete the project on time. • The contractor will be required to provide a bid bond in the amount of 5% of the total bid price. • The contract will be governed by the laws of the State of Texas, and any disputes will be resolved through litigation in a court of competent jurisdiction in Dallas County, Texas.