Bid #2526-23 Salinas Park Pickleball Court Crack Repair

The Gulf County Board of County Commissioners is seeking qualified contractors to repair cracks and resurface two existing pickleball courts at Salinas Park. The work includes concrete crack repair, resurfacing, and ensuring the courts are ready for public use within a 30‑day completion window. Liquidated damages of $250 per day apply for late completion. Bids must be sealed and submitted by the deadline, with electronic submissions also accepted via the County’s online bidding platform. • Repair cracks in two pickleball courts and apply new surface coating. • Complete the project within 30 days of receiving the Notice to Proceed; $250/day liquidated damages for delays. • Submit sealed bid (original + 2 copies) by July 22, 2026 4 PM EDT; electronic bids accepted through the County’s portal.