Courtney Bend WTP Reclaim Basin Restoration

The City of Independence, MO is seeking a qualified contractor to fully restore Wash Water Reclaim Basin No. 2 at the Courtney Bend Water Treatment Plant. The work includes removal and disposal of accumulated lime residuals, excavation, grading, site restoration, compliance with environmental permits, and seeding of the restored area. The contractor must provide all labor, equipment, materials, and expertise, secure necessary permits, and complete the project within 120 calendar days of notice to proceed. Bids are submitted electronically via www.publicpurchase.com; a non‑mandatory pre‑bid meeting/site visit is scheduled for September 3, 2026. • Scope: lime‑residual removal, earthwork, grading, disposal, erosion control, and reseeding. • Required qualifications: minimum five years in heavy civil construction, water‑treatment infrastructure, or residuals management. • Bonds: one‑year payment, performance and maintenance bond required. • Schedule: start anticipated Fall 2026; 120‑day completion window. • Submission deadline: September 9, 2026 3:00 PM EDT (online only). • Pre‑bid meeting: September 3, 2026 9:00 AM (non‑mandatory, also serves as site visit). • Liquidated damages: $300 per day for delays attributable to the contractor.