Description
The Texas Juvenile Justice Department (TJJD) is seeking a qualified respondent to provide all labor, materials, equipment, and services necessary for the installation and removal of HVAC upgrades for the Evins State Juvenile Correctional Facility. The scope of work includes demolition and replacement of sixty-two existing Split Units, installation of new ductwork, and associated structural, electrical, and plumbing work. The respondent must provide a detailed response package demonstrating their construction expertise and ability to offer TJJD a best-value contract to execute the Evins HVAC Project. Some key points to consider include:
• The respondent must have all applicable up-to-date licenses/certifications, necessary insurance, and required bonds.
• The work shall include delivery, setup, integration, and testing to ensure full operational functionality, as well as removal of replacements and all related waste from this project in accordance with applicable codes and TJJD specifications.
• The respondent must coordinate with the Maintenance Supervisor for the Evins State School for required electrical service upgrades on behalf of TJJD in a timely manner and order long lead time materials to avoid delay or pause in work.
• The work will be performed in occupied buildings and must be coordinated in a manner that will not cause major disruption to normal operations and take the necessary measures to ensure the youth in TJJD's care are safe and secure.