Description
The Texas Juvenile Justice Department (TJJD) is seeking a qualified respondent to provide all labor, materials, equipment, and services necessary for the installation and removal of HVAC upgrades for the Evins State Juvenile Correctional Facility. The scope of work includes demolition and replacement of sixty-two existing Split Units, installation of new ductwork, and associated structural, electrical, and plumbing work. The respondent must have at least five years of experience as a general contractor and provide references to the Texas Juvenile Justice Department. The project is expected to start on June 30, 2026, and be completed by June 29, 2027.
Key aspects of the project include:
* Installation of new rooftop air conditioning units
* Replacement of existing units
* Associated ductwork, controls, electrical, and plumbing modifications
* Coordination with the Maintenance Supervisor for required electrical service upgrades
* Work will be performed in occupied buildings and must be coordinated to avoid major disruption to normal operations
* The respondent must provide a detailed response package demonstrating their construction expertise and ability to offer TJJD a best-value contract